Wednesday, November 13, 2024
Hawai'i Free Press

Current Articles | Archives

Monday, August 8, 2016
Audit: How Hawaii VA Solar Project Delayed 21 Months
By News Release @ 7:49 PM :: 5905 Views :: Energy, Military

Audit of Green Management Program Solar Panel Projects

From Department of Veterans Affairs Inspector General for Audits and Evaluations August 3, 2016

…We reviewed 11 of 15 solar projects awarded from fiscal year (FY) 2010 through FY 2013 that were a work-in-progress as of May 2015. At the completion of our audit work in March 2016, only 2 of 11 solar projects were fully completed. In July 2016, VA informed us that 5 of 11 solar projects were fully completed. This occurred because of planning errors, design changes, a lengthy interconnection process, and contractor delays. As a result, VA did not increase renewable energy for those solar projects in the time frame planned and incurred additional costs through needed contract modifications.

What We Recommended

We recommended the Interim Assistant Secretary for Management implement additional controls to prevent solar panel conflicts, share best practices for executing timely interconnection agreements, implement power generation monitoring controls, and conduct lessons learned assessments.

Agency Comments

The Interim Assistant Secretary for Management concurred with the intent of two of the four recommendations and non-concurred for the remaining two recommendations. The Interim Assistant Secretary for Management also provided additional comments, which we addressed in this report….

Read … Full Report

FB: VA Drops Millions on Delayed Solar Power Projects

Honolulu, HI

VA awarded a solar panel project contract to SunWize Technologies for just over $600,000 in May 2012 with expected annual energy production of approximately 177,000 kilowatt hours. The solar panel project was delayed by approximately 21 months from the planned completion date of September 2013. Delays caused by SHPO concerns account for about 10 months of the solar panel project delay and represent the majority of additional project expenditures of just over $40,000. VA issued three modifications as a result of the SHPO findings, which resulted in a design change and compensation to the contractor for storage fees and project management.

The contracting office did not order a feasibility study since Hawaii is an optimal location for a solar panel system. If a feasibility study had been conducted, the additional time for the SHPO assessment could have been estimated and built into the project milestones. The remaining 11 months of delays are a result of miscellaneous issues including a 3-month delay for replacement of a subcontractor.

The solar panel project has been generating power since June 2015. However, we could not determine if expected annual energy production for the facility’s solar panel system was achieved as proposed by the contractor because the system had not been generating power for a year at the time of our review. Annual energy results for the facility’s solar panel system will not be available until July 2016.

Links

TEXT "follow HawaiiFreePress" to 40404

Register to Vote

2aHawaii

Aloha Pregnancy Care Center

AntiPlanner

Antonio Gramsci Reading List

A Place for Women in Waipio

Ballotpedia Hawaii

Broken Trust

Build More Hawaiian Homes Working Group

Christian Homeschoolers of Hawaii

Cliff Slater's Second Opinion

DVids Hawaii

FIRE

Fix Oahu!

Frontline: The Fixers

Genetic Literacy Project

Grassroot Institute

Habele.org

Hawaii Aquarium Fish Report

Hawaii Aviation Preservation Society

Hawaii Catholic TV

Hawaii Christian Coalition

Hawaii Cigar Association

Hawaii ConCon Info

Hawaii Debt Clock

Hawaii Defense Foundation

Hawaii Family Forum

Hawaii Farmers and Ranchers United

Hawaii Farmer's Daughter

Hawaii Federation of Republican Women

Hawaii History Blog

Hawaii Jihadi Trial

Hawaii Legal News

Hawaii Legal Short-Term Rental Alliance

Hawaii Matters

Hawaii Military History

Hawaii's Partnership for Appropriate & Compassionate Care

Hawaii Public Charter School Network

Hawaii Rifle Association

Hawaii Shippers Council

Hawaii Together

HiFiCo

Hiram Fong Papers

Homeschool Legal Defense Hawaii

Honolulu Navy League

Honolulu Traffic

House Minority Blog

Imua TMT

Inouye-Kwock, NYT 1992

Inside the Nature Conservancy

Inverse Condemnation

July 4 in Hawaii

Land and Power in Hawaii

Lessons in Firearm Education

Lingle Years

Managed Care Matters -- Hawaii

MentalIllnessPolicy.org

Missile Defense Advocacy

MIS Veterans Hawaii

NAMI Hawaii

Natatorium.org

National Parents Org Hawaii

NFIB Hawaii News

NRA-ILA Hawaii

Obookiah

OHA Lies

Opt Out Today

Patients Rights Council Hawaii

Practical Policy Institute of Hawaii

Pritchett Cartoons

Pro-GMO Hawaii

RailRipoff.com

Rental by Owner Awareness Assn

Research Institute for Hawaii USA

Rick Hamada Show

RJ Rummel

School Choice in Hawaii

SenatorFong.com

Talking Tax

Tax Foundation of Hawaii

The Real Hanabusa

Time Out Honolulu

Trustee Akina KWO Columns

Waagey.org

West Maui Taxpayers Association

What Natalie Thinks

Whole Life Hawaii